Terms & Conditions

These Terms and Conditions apply when you use the CliqThemes website, buy our plugins, or engage us for project work. By using our website or services, you agree to these terms.

Our services

CliqThemes builds WordPress plugins and themes, and develops custom web applications. We also sell our own free and Pro plugins. The specific work for any project is set out in a written scope or quote.

Quotes and scope

Quotes are based on the scope agreed at the time. Work that falls outside that scope may change the price and timeline, which we will confirm with you in writing before proceeding.

Payment

• Project work usually requires a deposit before we start, with the balance due at agreed milestones or on completion.
• Plugin purchases are charged at the price shown at checkout.
• Invoices are payable within the period stated on the invoice. Late payment may pause work.

Your responsibilities

To keep a project moving, you agree to provide content, access and feedback in good time, and to make sure you have the rights to any materials you give us to use.

Timelines

We give realistic timelines and update them weekly. Delays in feedback, content or third-party approvals can move delivery dates.

Intellectual property

Once a project is paid in full, the custom code and assets we produce for you are yours. We may reuse general techniques, libraries and non-confidential know-how on other projects. Our own plugins and pre-existing tools remain our property and are licensed to you, not sold.

Third-party services

Projects may rely on third-party services such as hosting, payment gateways and APIs. Those services have their own terms, and we are not responsible for their availability or changes.

Warranties and liability

We deliver our work with reasonable care and skill. To the extent permitted by law, our services are provided "as is", and our total liability for any claim is limited to the amount you paid us for the work it relates to. We are not liable for indirect or consequential losses. Nothing in these terms limits rights you have under the Australian Consumer Law.

Plugin licences and refunds

Plugin purchases and refunds are covered by our Refund Policy.

Termination

Either party may end a project with written notice. You agree to pay for work completed up to that point. Provisions that are meant to survive, such as payment and intellectual property, continue after termination.

Governing law

These terms are governed by the laws of New South Wales, Australia, and the courts of New South Wales have jurisdiction over any dispute.

Changes

We may update these terms from time to time. The current version will always be on this page.

Contact us

Questions about these terms? Email [email protected].